M/S.ESSAR OIL LTD. Vs HINDUSTAN SHIPYARD LTD. .
Bench: ANIL R. DAVE,VIKRAMAJIT SEN,PINAKI CHANDRA GHOSE
Case number: C.A. No.-003353-003353 / 2005
Diary number: 8723 / 2005
Advocates: E. C. AGRAWALA Vs
ANNAM D. N. RAO
Page 1
1
REPORTABLE
IN THE SUPREME COURT OF INDIA CIVIL APPELLATE JURISDICTION CIVIL APPEAL NO.3353 OF 2005
M/S ESSAR OIL LTD. ... APPELLANT VERSUS
HINDUSTAN SHIPYARD LTD. & ORS. ... RESPONDENTS
WITH CIVIL APPEAL NO.3355 OF 2005
J U D G M E N T
ANIL R. DAVE, J. 1. Being aggrieved by a common judgment dated 29th
September, 2004, delivered in Appeals Against Order
Nos.255 and 624 of 2003 by the High Court of Andhra
Pradesh at Hyderabad, these appeals have been filed
by M/s Essar Oil Ltd., who had been given a
sub-contract by the first respondent, Hindustan
Page 2
2
Shipyard Ltd., in respect of a contract which was
given to it by the Oil and Natural Gas Commission.
2. The facts giving rise to the present
litigation, in a nutshell, are as under:-
The Oil and Natural Gas Commission (hereinafter
referred to as ‘the ONGC’) had given a contract to
Hindustan Shipyard Ltd. to carry out work of
fabrication, skidding, sea fastening, transportation
etc. at various stations located in the coastal
areas of India. It is pertinent to note that the
contractor, Hindustan Shipyard Ltd., who is
respondent no.1 in both the appeals, had been
permitted to avail services of any other person for
doing the aforestated work entrusted to it. In
other words, it was open to respondent no.1 to
engage a sub-contractor for getting the work done.
Other respondents in these appeals are the
arbitrators, who are formal parties.
Page 3
3
3. In pursuance of the aforestated understanding
arrived at and the contract entered into between the
ONGC and Hindustan Shipyard Ltd. (who has been
referred to as ‘the respondent’ hereinafter), the
respondent had entered into a contract with M/s
Essar Oil Ltd., who is the appellant in both these
appeals. Thus, the appellant was a sub-contractor
in respect of the contract which the respondent had
to fulfill for the ONGC.
4. It appears that for the sake of convenience and
so as to obviate certain financial difficulties of
the respondent, certain payments had been made to
the appellant directly by the ONGC. The appellant,
upon getting certain work done under the
sub-contract and upon getting necessary certificates
with regard to the quality and quantity of the work
done from the respondent, had received some payment
from the ONGC on the strength of those certificates.
Page 4
4
5. In the process of carrying out the contract,
the appellant was not paid by the respondent for the
work done and therefore, a dispute had arisen
between the appellant and the respondent. Let us
not look at the nature of the dispute or the amount
claimed or the liability with regard to making
payment to the appellant at this stage, suffice it
to state that there was an Arbitration Agreement
between the appellant and the respondent and
therefore, the dispute had been referred to the
Arbitral Tribunal. Respondent nos.2, 3 and 4 are
the Arbitrators, who had made the Award with regard
to which we will discuss presently.
6. Thus, the dispute with regard to non-payment
and some other disputes had been referred to the
Arbitral Tribunal consisting of Respondent nos.2, 3
and 4. It is pertinent to note here that the ONGC,
who had given a contract to the respondent, was not
before the Arbitral Tribunal because the ONGC was
Page 5
5
not a party to the Arbitration Agreement entered
into between the appellant and the respondent. The
question which was involved in the said dispute was
not only with regard to determination of the amount
to be paid to the appellant, but was also with
regard to determination of a person who was liable
to make payment to the appellant.
7. After hearing the concerned parties, the
Arbitral Tribunal made an Award, but all the three
Members of the Tribunal could not come to the same
conclusion. The majority i.e. two Members of the
Tribunal came to the conclusion that there was no
privity of contract between the appellant and the
ONGC; and the ONGC was not a party to the contract
between the appellant and the respondent. In the
aforestated circumstances, the ONGC, according to
the majority view, could not be held liable for
making payment to the appellant and the liability to
make payment to the appellant was that of the
Page 6
6
respondent. It was also held by the majority that
the appellant could not even sue the ONGC for the
unpaid amount. Accordingly, the Award was made. At
this stage, we are not concerned with the other
facts and the amount awarded by the majority of the
Tribunal.
8. On the other hand, the dissenting Member, who
was in minority, was of the opinion that there was a
contract between the appellant and the ONGC and
therefore, the ONGC was liable to make payment to
the appellant, but he expressed an opinion to the
effect that the respondent should be directed to
make payment to the appellant only if the respondent
is paid the unpaid amount by the ONGC. Thus, the
minority view was that the liability to make payment
to the appellant was that of the ONGC, but as the
ONGC was not a party before the Tribunal, the proper
course open to the appellant was to take appropriate
Page 7
7
legal action against the ONGC for recovery of the
amount due and payable to the appellant.
9. The respondent was aggrieved by the Award of
the Arbitral Tribunal as according to the majority
view of the Tribunal, the respondent was liable to
make payment to the appellant. In the circumstances,
the respondent filed OP NoS.989 of 2001 and 96 of
2002 before the Principal District Judge,
Visakhapatnam, under Section 34 of the Arbitration
and Conciliation Act, 1996.
10. The Principal District Judge, Visakhapatnam,
decided both the Original Petitions by orders dated
10th October, 2002 and 1st November, 2002,
respectively. The learned Principal District Judge
confirmed the award on the issues with which we are
concerned, but he remanded the matter to the
Arbitral Tribunal on the issues regarding counter
claim etc., with which we are not concerned in this
case.
Page 8
8
11. Being aggrieved by the aforestated two orders
passed in two Original Petitions, the respondent
filed Appeals Against Order Nos.255 and 624 of 2003
before the High Court of Andhra Pradesh and the High
Court allowed the appeals by a common judgment dated
29th September, 2004, validity of which has been
challenged before this Court in these appeals.
12. The High Court came to a conclusion that there
was a tripartite agreement among the ONGC, the
appellant and the respondent. The High Court had
relied upon some letters written by the appellant to
the ONGC and therefore, the ONGC was also treated as
a party to the contract. It also held that as the
ONGC was a party to the contract, it ought to have
been made a party before the Arbitral Tribunal but
as the ONGC was not represented before the Arbitral
Tribunal, the Award made by the Tribunal was bad in
law. The Award deserved to be set aside by the
Principal District Judge but he did not and
Page 9
9
therefore, the orders passed in the Original
Petitions filed before the learned Principal
District Judge were also bad in law and accordingly
the Award and the orders passed in the Original
Petitions were quashed and set aside.
13. The main issue which is involved in these
appeals is about ascertainment of a person, who is
liable to make payment to the appellant. There is
no dispute with regard to quality or quantity of the
work done by the appellant at this stage. It is
not in dispute that the appellant has not been paid
the amount payable to it. It is also not in dispute
that the appellant had been engaged by the
respondent in pursuance of a contract entered into
between the respondent and the ONGC and it was open
to the respondent to avail services of any other
person for doing the work entrusted to it by the
ONGC. In the light of the aforestated undisputed
facts, the question is only with regard to
Page 10
10
determination of liability of the person who has to
make payment to the appellant.
14. The learned counsel appearing for the appellant
had vehemently submitted that the view taken by the
majority of the Arbitral Tribunal being correct, the
High Court ought not to have interfered with the
said view. So as to substantiate his submission,
the learned counsel had mainly submitted that there
was no privity of contract between the appellant and
the ONGC. The appellant had performed the work of
the ONGC in pursuance of a contract given to it by
the respondent, which was a sub-contract in nature.
In absence of any contract between the ONGC and the
appellant, the appellant could not have made any
claim before the ONGC and as there was no contract
between them, it was also not possible for the
appellant to make the ONGC a party before any Court
or Authority for recovery of the amount payable to
Page 11
11
it in pursuance of the sub-contract given by the
respondent.
15. It had been fairly admitted by the learned
counsel appearing for the appellant that very often
payments were made to the appellant by the ONGC. It
had further been submitted that the payments were
made by the ONGC so as to facilitate the appellant
and to get the work of the contract done smoothly.
Every time when payment was made by the ONGC to the
appellant, the ONGC used to debit the account of the
respondent i.e. the amount so paid by the ONGC to
the appellant was treated by the ONGC as if the said
payment was made by the ONGC to the respondent.
Thus, so as to obviate a long procedure and to
expedite payment to the appellant, who was actually
doing the job for the ONGC, instead of the ONGC
paying to the appellant through the respondent, the
ONGC was paying directly to the appellant.
Page 12
12
16. The learned counsel for the appellant had with
great stress submitted that there was not a single
contract between the appellant and the ONGC and
there was no tripartite contract among the
appellant, the respondent and the ONGC, whereby the
ONGC was made liable to pay the appellant in respect
of the work done by it.
17. For the aforestated simple reason, it had been
submitted by the learned counsel for the appellant
that the majority view of the Arbitral Tribunal was
correct and the respondent is liable to make payment
to the appellant with whom it had entered into the
contract. It had been further submitted by the
learned counsel that in view of the aforestated
factual and legal position, the appeals deserve to
be allowed and the respondent should be made liable
to make payment to the appellant.
18. On the other hand, the learned counsel for the
respondent had submitted that the ONGC was liable to
Page 13
13
make payment to the appellant and therefore, there
is no liability on the part of the respondent to
make payment to the appellant.
19. It had further been submitted by the learned
counsel for the respondent that it is not necessary
that in each and every case the contract should be
in writing. The contract can be very well inferred
by the act or conduct of the parties, whereby
impliedly a party undertakes to make good a
liability to make payment to someone. According to
the learned counsel, even in the instant case, there
was an implied contract amongst the appellant, the
respondent and the ONGC and therefore, it was the
liability of the ONGC to make payment to the
appellant.
20. The learned counsel for the respondents had
drawn our attention to correspondence exchanged
between the ONGC and the respondent. He had
specially referred to a letter dated 25th October,
Page 14
14
1991 addressed by the respondent to the ONGC,
wherein it was stated that the ONGC had desired to
make payment directly to the appellant in pursuance
of meetings convened among the representatives of
the respondents and the ONGC. He had also submitted
that some of the letters written by the ONGC to the
respondent clearly denoted that the ONGC had
accepted the liability to make payment to the
appellant and therefore, there was no liability on
the part of the respondent to make any payment to
the appellant. He had further submitted that the
subsequent conduct of the ONGC of making direct
payment to the appellant established the fact that
the ONGC had undertaken the liability to make
payment to the appellant. The aforestated letter
dated 25th October, 1991 and other letters which had
been exchanged between the respondent and the ONGC
were placed on record to show that there was a
contract between the ONGC and the appellant.
Page 15
15
21. For the aforestated reasons, it had been
submitted by the learned counsel for the respondent
that the view of the High Court that the ONGC was
liable to make payment to the appellant is correct
and therefore, the appellant should take appropriate
action against the ONGC for recovery of the unpaid
amount. The learned counsel had, therefore,
submitted that the view taken by the High Court is
absolutely correct and the respondent is no more
liable to make any payment to the appellant.
22. We have heard the learned counsel for the
parties at length and have also considered some
judgments cited by them and the documents which had
been placed on record and relied upon by them.
23. Upon hearing the learned counsel and looking at
the contract entered into between the appellant and
the respondent and upon perusal of other letters, we
believe that the view expressed by the High Court
cannot be accepted.
Page 16
16
24. It is true that the ONGC had made payment to
the appellant directly on several occasions. Upon
perusal of the correspondence, we find that some
understanding, but not amounting to any agreement or
contract, was arrived at between the ONGC and the
respondent for making direct payment to the
appellant, possibly because the respondent was not
in a position to make prompt payments to the
appellant. It also appears that on account of the
delay in making payment to the appellant, the work
of the ONGC was likely to be adversely affected.
The ONGC was interested in getting its work done
promptly and without any hassles. In the
circumstances, upon perusal of the correspondence,
which had taken place between the ONGC and the
respondent, it is clear that so as to facilitate the
respondent, the ONGC had made payments on behalf of
the respondent to the appellant directly.
Page 17
17
25. Simply because some payments had been made by
the ONGC to the appellant, it would not be
established that there was a privity of contract
between the ONGC and the appellant and only for that
reason the ONGC cannot be saddled with a liability
to pay the amount payable to the appellant by the
respondent.
26. It is also pertinent to note that the
Arbitration Agreement was only between the appellant
and the respondent. The ONGC was not a party to the
Arbitration Agreement. When a dispute had arisen
between the appellant and the respondent in relation
to payment of money, the appellant had initiated the
arbitration proceedings. As the ONGC was not a
party to the Arbitration Agreement, it could not
have been represented before the Arbitral Tribunal.
If the ONGC was not a party before the Arbitral
Tribunal, the Tribunal could not have made any Award
making the ONGC liable to make payment to the
Page 18
18
appellant. In the aforestated factual and legal
position, the Arbitral Tribunal could not have made
the ONGC liable in any respect and rightly, the
majority view of the Arbitral Tribunal was to the
effect that the ONGC, not being a party to any
contract or Arbitration Agreement with the
appellant, could not have been made liable to make
any payment to the appellant.
27. We are in agreement with the view expressed by
the majority of the Arbitral Tribunal. In our
opinion, the High Court had committed an error by
not considering the above facts and by observing
that the appellant will have to take legal action
against the ONGC for recovery of the amount payable
to it. If one looks at the relationship between the
appellant and the respondent, it is very clear that
the respondent had given a sub-contract to the
appellant and in the said agreement of sub-contract,
the ONGC was not a party and there was no liability
Page 19
19
on the part of the ONGC to make any payment to the
appellant. Moreover, we could not find any
correspondence establishing contractual relationship
between the ONGC and the appellant. In the
circumstances, the ONGC cannot be made legally
liable to make any payment to the appellant. As
stated hereinabove, only for the sake of convenience
and to get the work of the ONGC done without any
hassle, the ONGC had made payment to the appellant
on behalf of the respondent without incurring any
liability to make complete payment on behalf of the
respondent.
28. The learned counsel appearing for the appellant
failed to show any document in the nature of a
contract entered into between the appellant and the
ONGC whereby the ONGC had made itself liable to make
payment to the appellant. Even when the payment had
been made by the ONGC, it was very clear that the
payments were made on behalf of the respondent as
Page 20
20
the ONGC was debiting the account of the respondent
by the amount paid to the appellant. It is
important that the payment was made to the appellant
only upon certification of work done by the
respondent. The ONGC had given a contract to the
respondent. The ONGC had never entered into any
contract with the appellant and therefore, it did
not rely upon any certification or any statement
made by the appellant in relation to quantum of work
done by the appellant. This fact also shows that
the ONGC was concerned with the work which had been
approved by the respondent and instead of making
payment to the respondent, the ONGC had made payment
to the appellant on behalf of the respondent, though
there was no legal obligation on the part of the
ONGC to make such a payment to the appellant.
29. For the aforestated reasons, we do not agree
with the view expressed by the High Court and the
impugned judgment delivered by the High Court is set
Page 21
21
aside. The ONGC shall not be liable to make
payment, as rightly decided by the Arbitral
Tribunal, to the appellant but the payment shall
have to be made by the respondent, who had given a
sub-contract to the appellant. Majority view of the
Arbitral Tribunal on the above issue is confirmed
and the view of the High Court is not accepted. The
respondent shall accordingly make payment to the
appellant.
30. For the reasons enumerated hereinabove, the
appeals are allowed with no order to costs.
…………………………………………………….J
(ANIL R. DAVE)
…………………………………………………….J (VIKRAMAJIT SEN)
…………………………………………………….J (PINAKI CHANDRA GHOSE)
NEW DELHI; JULY 2, 2015.