DEVI MULTIPLEX Vs STATE OF GUJARAT .
Bench: ANIL R. DAVE,UDAY UMESH LALIT
Case number: C.A. No.-006478-006478 / 2009
Diary number: 21165 / 2009
Advocates: VISHAL GUPTA Vs
HEMANTIKA WAHI
Page 1
CORRECTED REPORTABLE
IN THE SUPREME COURT OF INDIA
CIVIL APPELLATE JURISDICTION
CIVIL APPEAL NO.6478 OF 2009
DEVI MULTIPLEX & ANR. …. Appellants
Versus
STATE OF GUJARAT & ORS …. Respondents
WITH
CIVIL APPEAL NOs.6479/2009, 6480/2009, 6481/2009, 6482/2009, 6483/2009, 6484/2009, 6485/2009, 6487/2009,
6488/2009, 6489/2009, 6490/2009 AND 6491/2009
J U D G M E N T
Uday Umesh Lalit, J.
1. Civil Appeal 6478 of 2009 is directed against the judgment and
order dated 26.06.2009 passed by the High Court of Gujarat at
Ahmedabad in Special Civil Application No.18692 of 2005 to the
extent it dismissed the challenge to the order passed by respondent
no. 3 dated 20.07.2005 rejecting the application of the appellants for
Page 2
extension of time under Clause 10 of New Package Scheme of
Incentives for Tourism Projects, 1995-2000. Similar challenge stands
raised in other civil appeals against Orders rejecting their applications
for extension of time. Since Civil Appeal No.6478 of 2009was taken
as the lead matter, facts relating thereto are dealt with in detail
hereafter.
2. On 20.12.1995 Government of Gujarat announced policy
named “New Package Scheme of Incentives for Tourism Projects,
1995-2000” (hereafter referred to as the Scheme) with a view to make
available all fiscal and non fiscal incentives, reliefs and concessions
enjoyed by industries to ‘Tourism’ which was accorded the status of
an industry, in order to give a boost to tourism sector by attracting
higher investment in the areas with tourism potential and to generate
employment opportunities. Under Clause 2, the Scheme came into
operation on 1.8.1995 and was to remain in force for a period of five
years upto 31.07.2000. Under Clause 3, to be eligible, a new tourism
unit ought to be registered after 1.8.1995. Clause 4.7 dealt with
effective steps which such unit was expected to undertake. Under
Clause 5, after taking initial effective steps a tourism unit could apply
to the Director of Tourism for registration. All projects had to conform
2
Page 3
to the specifications and requirements spelt out in Appendix B which
Appendix dealt with various categories of tourism units and Item 22
thereof pertained to Entertainment Complexes including multi cinema
theater complexes or multiplexes. Clause 7 categorised tourism units
in four categories, namely, Prestigious Tourism Units, Large Scale
Tourism Units, Small Scale Tourism Units and Tiny Tourism Units
with minimum fixed capital investment of Rs. 10 Crore, 90 lakhs, 10
lakhs and less than 10 lakhs respectively. Clause 8 dealt with
incentives and stated that a tax holiday of 5-10 years would be
available in respect of exemptions from (i) Sales Tax (ii) Turnover Tax
(iii) Electricity Duty (iv) Luxury Tax and (v) Entertainment Tax, upto
100% of capital investment. In clause 8.1 it was stated that the
quantum of incentives would not exceed 100% of eligible capital
investment and it further stated the period of eligibility in respect of
Prestigious Tourism Unites, Large Scale Tourism Units, Small Scale
Tourism Units and Tiny Tourism Units to be 10 years, 8 years, 6 years
and 5 years respectively. Clause 9 dealt with composition of
sanctioning authority whereunder State Level Committee was
competent to issue eligibility certificate in respect of Prestigious and
Large Units while District Level Committee was to issue eligibility
3
Page 4
certificate for all Small Scale and Tiny Tourism Units. The procedure
for registration tourism units for incentives was detailed in Clause 10.
3. Clauses 4.7 and 10 of the Scheme are quoted hereunder:-
“4.7 EFFECTIVE STEPS
The effective steps shall comprise
(a) initial effective steps which shall include:
i) Effective possession of land by an eligible unit free from all encumbrances.
ii) Registration in respect of company/Cooperative Society/Trust in respect of a partnership firm, evidence of execution of partnership deed and filling of requisite application with payment of necessary registration fees with the Registrar of Firms.
iii) Submission of project report specifically mentioning the category of tourism activity (coverage) and the incentive that are proposed to be availed of by the eligible unit with all relevant details.
iv) Copy of application duly acknowledged by all statutory and executive authorities from which permission is required.
(b) final effective steps shall mean and include:
i) Clearance, if any, from Central/State Government and other authorities concerned for implementing the project.
ii) Tying up of the means of finance for the project to the satisfaction of the incentive sanctioning authority.
4
Page 5
iii) Acquisition of fixed assets at site to the extent of 10% of the total fixed assets as envisaged for the project, and
iv) Evidence regarding expenditure on the project, including advances and pre-operative expenses paid, aggregating to at least 25 percent of the capital cost envisaged for the project.
10. PROCEDURE FOR REGISTRATION OF TOURISM UNITS FOR INCENTIVES: All tourism units eligible for the Scheme will apply to the Director of Tourism in a prescribed Form. The Directors of Tourism will scrutinizes the application and will issue temporary and permanent registration adopting the following procedure:
a) Director of Tourism shall give provisional registration in the first instance upto 2 years to the eligible unit after scrutinizing the application received by him under the Scheme.
b) If such a unit is not in a position to start commercial operation during the initial validity period the unit will have to apply with the progress report to the State Level Committee which is authorized to grant extension upto six months at a time or a total period of 2 years after examining the difficulties experienced by the individual unit in implementing the project and also record the reasons thereof in writing.
c) The units which are unable to go into operation after it has been given extension under para (b) above will have to apply to Government the reasons for the delay. Such application will have to be forwarded by the director of tourism, who will carry out physical inspection of projects and report to government for decision. If the director of tourism is satisfied that the
5
Page 6
steps to implement the project are adequate he shall inform the Government about the same.
d) The State Government on examination of details made available by the director of tourism may decide to extend or reject the registration depending upon the merit of each case. The decision of Government in this regard will be final and binding on the party.
e) The unit will become eligible to apply for provisional or temporary registration only after taking initial effective steps as stipulated in para 4(7)(a).
f) The eligible unit will be registered permanently only after the commencement of commercial operation and completion of the project.”
4. The State Government, in exercise of powers conferred upon it
under Section 29 of the Gujarat Entertainment Tax Act, 1977 (Act 16
of 1977), issued Notification dated 14.02.1997 which was published
in the Government Gazette of even date. The relevant part of the
Notification was as under:
“Whereas the Government of Gujarat has introduced a New Package Scheme of incentives for Tourism Projects 1995-2000, under the “New Package Scheme for incentives for Tourism Projects 1995-2000, under the “New Tourism Policy, 1995” vide Government Resolution, Information, Broadcasting and Tourism Department No.NTP-1095-1983-C, dated the 20th December, 1995 (hereinafter referred to as “the aid resolution”):
6
Page 7
And whereas the Government of Gujarat considers it necessary so to do in the public interest:
Now, therefore, the exercise of powers conferred by sub-sec. (1) of Section 29 of the Gujarat Entertainment Tax Act, 1977 (Guj. 16 of 1977), (hereinafter refrred to as “the said Act”) and in supersession of Government Notification, Information, Broadcasting and Tourism Department No. (GHT.91.45) MNR-1391-285-E, dated the 24th December, 1991 the Government of Gujarat hereby exempt wholly the tax on the entertainment which fulfils the criteria laid down in Appendix-B of the said resolution (hereinafter referred to as the eligible entertainment) during the eligible period or upto the period of expiry of the limits of incentives, whichever is earlier, to the extent referred to in para 8.1 of the said resolution…………………………………….. …………………………………………………………… ……………………………………………………..”
Paragraph 17 of the Notification stated that the exemption
under said Notification would be subject to all terms and conditions
referred to in Government Resolution dated 20.12.1995 in the Scheme
and further conditions stipulated in the Notification.
5. The appellants being desirous of setting up a multiplex and
avail the incentives under the Scheme took effective steps as stated in
the Scheme and the Notification dated 14.02.1997 and applied for
Temporary Registration Certification (TRC for short). Said
application was examined by the concerned authorities and TRC was
7
Page 8
granted on 17.09.1999 and the same was sent to the appellants under
covering letter dated 04.11.1999. In pursuance thereof the appellants
started constructing the multiplex in accordance with the Scheme.
6. On 28.06.2000 Government Resolution No.NTP/1098-3219/C
was issued by the State Government seeking to clarify
incidental/ancillary aspects as regards treatment of certain cases
covered under the Scheme. Clause A of the Resolution stated that an
application for TRCs under the existing policy would be accepted till
31.07.2000 and TRCs would be issued provided initial effective steps
were taken on or before 31.07.2000. Clause B of the said Resolution
was as under:
“B. ADHOC/FINAL ELIGIBILITY ERTIFICATE:
(1) All the units to whom TRC has already been issued under the guidelines of Tourism Policy 1995-2000, shall apply for the Eligibility certificate within 180 days from the date of commencement of commercial activities.
(2) All the units to whom TRC has been issued & have not commenced commercial activities on or before 31.07.2000 shall be considered as pipelines case.
(3) The units falling under the pipeline cases shall complete the respective project within the time-limit given below.
a) Tiny Project 1 year w.e.f. 31/7/2000
8
Page 9
b) Small Project 1 year w.e.f. 31/7/2000 c) Prestigious Project 2 year w.e.f. 31.7.2000 d) Large project 2 year w.e.f. 31.7.2000
No further extension or relaxation shall be available to pipeline cases.
(4) The unit falling under the pipeline cases who fails to complete the project as stipulated above shall not be eligible for any incentive Adhoc or Final as per tourism Policy 1995-2000.
(5) No investment made after operative period or Scheme, i.e. 31.7.2000 shall be considered as eligible investment. However, in case of projects not completed and commissioned up to 31.7.2000 the investment made during extended period mentioned above shall be considered while computing eligible investment.
(6) The validity period of the TRC issued under the existing policy 1995-2000 shall be two years from date of issue or expiry of operative period or policy, i.e. 31.7.2000 whichever is earlier.
(7) The pipeline cases, once rejected shall not be eligible to apply again for incentives under the Tourism Policy 1995-2000.”
The Scheme was extended upto 30.09.2000 and later upto
30.11.2000 vide Resolutions dated 31.07.2000 and 30.09.2000
respectively issued by the State Government.
7. On 26.01.2001 a massive earthquake took place in the State
resulting in collapse of number of buildings and structures. This
9
Page 10
caused suspension of the process of issuing development permissions,
for the purposes of maintaining structural safety standards in
Development Control Regulations under the provisions of the Gujarat
Town Planning and Urban Development Act, 1976. On 27.03.2001 it
was directed by the State Government that all development
permissions must adhere to structural safety norms as stated in
annexure to said order dated 27.03.2001 and that even with respect to
the existing development permissions, necessary certification
regarding structural stability and strengthening ought to be issued by
Structural Engineers having requisite qualifications. The appellants
submitted building plans along with the requisite structural stability
certificate. The approval was accorded by the Municipal Corporation
in October 2001 and the appellants resumed construction work. Since
more than a year was lost because of subsequent changes in building
norms, the appellants applied on 11.12.2001 for grant of extension for
completing the project pointing out the aforesaid difficulties. It was
stated that as on the date, the appellants had incurred expenditure to
the tune of Rs.91.25 lakhs for which a certificate of the Chartered
Accountant was enclosed. Photographs of the completed civil works
were also enclosed.
10
Page 11
8. Around 26.02.2002 large scale communal riots took place in the
State and Naroda (where the project of the appellant is located) was
one of the worst affected areas. Normal civil life was disrupted for a
considerable time, the labour force had left the site and accordingly, as
per the appellants, no construction could take place for more than four
months. On 04.04.2002 in its 12th meeting, State Level Committee
considered the application dated 11.12.2001 preferred by the
appellants. It clarified that the date of TRC in case of the appellants
shall be 4.11.1999. Keeping in view the delay in continuation of
operation due to earthquake and so also the progress made by the
appellants, the Committee granted extension in validity period of TRC
by six months which decision was communicated on 15.04.2002. The
appellant wrote on 24.02.2002 stating that though the extension was
granted by the State Level Committee, the appellants could effectively
get only 17 days out of the extension of six months. The appellants
informed that the civil work was complete and the electrification and
air-conditioning work was in progress. It was further stated that as on
that date Rs.1.11 crores were spent on various items of capital work,
as supported by certificate from the Chartered Accountant and prayed
for further extension of four months. By subsequent letter dated
11
Page 12
19.08.2002 it was stated that the civil work and the electrification was
complete and the ducting and air-conditioning work was on the verge
of completion. The status of investment as on that date was said to be
more than Rs.3.21 crores, as supported by the certificate from the
Chartered Accountant. The appellants then requested for extension of
six months instead of four months as was prayed earlier vide request
dated 29.04.2002.
9. The State Level Committee in its 13th meeting held on
21.09.2002 discussed the provisions of extension in validity period of
TRCs as per the policy. It felt that the implementation of various
projects was affected on account of the earthquake and subsequent
finalisation of Development Control Rules and Regulations for the
earthquake resistant building structures. As regards the application of
the appellants, the Committee found that the delay in commencing the
operation due to earthquake and in completing the operation due to
riots was justifiable and that the physical progress of the project was
satisfactory. However, it took the view that extending the validity
period would result in extension beyond 31.07.2002 and as such the
matter was required to be deferred till the Government took a decision
on modification of GR dated 28.06.2000.
12
Page 13
10. The appellants vide letter dated 30.10.2002 reiterated their
request for extension which was repeated by letters dated 13.12.2002
and 22.04.2003. On 20.06.2003 the Commissioner of Tourism
informed that a proposal for amendment of GR dated 28.06.2000 was
sent and the matter was being considered at the governmental level. It
was stated that the eligibility as per TRC issued to the appellants was
in force and that their project was still eligible. The appellants
commenced commercial operations on 11.07.2003 and applied for
grant of appropriate eligibility certificate on 04.11.2003.
11. In June 2004 Multiplex Association of Gujarat filed Special
Civil Application No.5574 of 2004 on behalf of its members in the
High Court seeking appropriate directions for grant of eligibility
certificate to its members. The High Court by its order dated
22.06.2004 directed the State Government to decide the
applications/representations for extension of time. Thereafter, on
22.07.2004 the Commissioner of Tourism issued a show cause notice
calling upon the appellants why their application dated 04.11.2003 for
grant of eligibility certificate should not be rejected. Relying on the
GR dated 28.06.2000, it was stated that the project was not completed
13
Page 14
by 31.07.2002 and as such the appellants did not qualify for the
benefit of the Scheme dated 20.12.1995. The show cause notice was
replied by the appellants. On 20.07.2005 the application for grant of
eligibility certificate was rejected stating the following reasons:
“1. Sufficient time extension has already been given for starting commercial activities of the project.
2. Further extension of time limit would lead to undue burden on the State’s Exchequer.
3. Multiplicity of multiplexes beyond the requirement in the State.”
12. The aforesaid order dated 20.07.2005 was challenged by the
appellants by filing Special Civil Application No.18692 of 2005 in the
High Court seeking declaration that period for starting commercial
operation as envisaged in the Scheme stood extended upto 11.07.2003
and that the appellants were entitled to be issued eligibility certificate
and to all incentives under the Scheme. The High Court while
rejecting the submissions observed that the operative period of the
Scheme came to an end on 30.11.2000 by which time the appellants
had not commenced commercial operation and that the appellants
were not entitled to any benefits or incentives under the Scheme. It
found that the time for completing the project and commencing the
14
Page 15
commercial operation would stand extended as a result of
Government Resolution dated 28.06.2000 only upto 31.07.2002 and
upto 30.11.2002 in view of Government Resolutions dated 31.07.2000
and 30.09.2000, that there could be no further extension of time limit
and that since the commercial operations had not commenced even
within such extended time period, the claim of the appellants was
rightly rejected. It observed that in the facts and circumstances of the
case there could be no application of the principles of Promisory
Estoppel. The present appeal by Special Leave seeks to challenge the
view so taken by the High Court. During the pendency of the matter
this Court had directed the appellants and similarly situated multiplex
theatre owners to keep paying the current taxes and to deposit the
outstanding dues as on 31.07.2009 in six equal quarterly installments
with interest @ 9 per cent on reducing balance.
13. Appearing for the appellants, Mr. Rakesh Dwivedi, learned
Senior Advocate submitted that the incentives provided in Clauses 8
and 8.1, and the procedure prescribed for registration in Clause 10
formed the core of promise and representation on part of the State
Government based on which eligible units including that of the
appellants had altered their position and made huge investments in
15
Page 16
Large Scale Tourism Units. He submitted that such units could not
now be told that the non fiscal benefits of extension of validity period
would not be granted to them despite they have been fulfilled the
conditions of satisfactory progress. It was further submitted that
Clause 10(b) and more particularly the expressions “in the first
instance” and “initial validity period” in said Clause 10 (b) promised
an over all validity period of four years; the initial validity period
being two years granted straight away under TRC while the
subsequent period of two years could be granted depending upon the
progress report and difficulties experienced. He submitted that the
notification dated 14.2.1997 was issued under Section 29 of Act 16 of
1977 incorporating the terms and conditions of the Scheme dated
20.12.1995 and as such Clause 10 of the Scheme had acquired a
statutory status. In his submission, G.R. dated 28.06.2000 was a mere
resolution not being translated into similar notification under Section
29, and therefore said GR dated 28.06.2000 could not detract or
derogate from statutory notification dated 14.2.1997. On merits, it
was submitted that the reasons in the letter of rejection dated
20.07.2005 were incorrect and irrelevant. He stated that out of 108
TRCs issued under the Scheme, only in 22 or 23 cases the projects
16
Page 17
were completed and commercial operations had started. Evidently, the
State Government must have considered that the burden with respect
to 108 TRCs could comfortably be borne, keeping in mind the
advantages flowing from establishment of the projects. Further, three
projects had shut down after they became operational. In the
circumstances, the reasons regarding undue burden on the Exchequer
and requirement of Multiplexes in the State as stated, were absurd and
baseless.
14. Mr. Pritesh Kapur learned Advocate appearing for the State
submitted that the Scheme was to remain in force up to 31.07.2000
which period was further extended up to 30.11.2000 and that the
Scheme including Clause 10 in its entirety ceased to be operative
thereafter. In the submission of the learned counsel, the right to seek
an extension of the validity period beyond the cut off date would
survive only if such right was an accrued right, which was not so in
the present case. He further submitted that GR dated 28.06.2000,
rather than detracting from the Scheme granted further extension to
such units and as such cases for extension after the period of operation
of the Scheme had come to an end must and ought to be governed by
G.R. dated 28.06.2000 alone and that since said G.R. did not
17
Page 18
contemplate any extension, the State Level Committee was right in
not exercising any powers for grant of extension. The Government
was also right in his submission, in taking a policy decision in not
granting any further extensions.
15. Mr. Rakesh Dwivedi learned Senior Advocate in rejoinder
submitted that incentives under Clause 8 which span beyond 5 years
and up to 10 years, were designed to survive even after expiry of the
Scheme. He further submitted that in a case where TRC was granted
towards the end of the operative period of the Scheme, the final
effective steps would necessarily have to be taken after the expiry of
the Scheme and thus the Scheme itself contemplated that the actions
under various clauses would continue to be undertaken even after the
expiry of the Scheme. In his submission the concept of “accrued
right” is to be seen in the context of Section 6 of the General Clauses
Act which may not strictly apply in the present case. It was submitted
that in any case positive acts in the form of huge investments for
setting up the projects having been undertaken during the initial
validity period of the Scheme, the entitlement to claim benefit of
consideration of case for extension under the Scheme was an “accrued
right”.
18
Page 19
16. Reading of the Scheme shows that to be eligible for the
incentives under the Scheme, a new project ought to have obtained
registration after 1.8.1995 and taken initial effective steps under
Clause 4.7(a) which inter alia included effective possession of land
free from all encumbrances and submission of Project Report. It is
only thereafter that an intending unit could apply and be given
provisional registration under Clause 10(a). Said clause indicates that
such provisional registration “in the first instance” would be up to two
years. If the unit was not in a position to start commercial operation
during this initial validity period of two years, it would be entitled to
apply with progress report to the State Level Committee for extension,
which could be granted up to six months at a time or a total period of
two years after examining the difficulties experienced in
implementing the project. This first level of extensions for a total
period of two years could be granted by the State Level Committee
and even if a unit was unable to go into operation after availing such
extensions, it could still apply to the Government for further
extension. Clauses 8 and 8.1 dealt with incentives and period of
eligibility which would go up to ten years after a unit was found to be
fully eligible. These clauses clearly show that such stages or
19
Page 20
eventualities would survive even after the expiry of period of the
operation of the Scheme. The reading of the Scheme further shows
that no fresh application and TRCs could be granted after the period
of operation but those who had crossed the threshold and were given
TRC, could have the full benefit of the stages contemplated in Section
10. In our considered view, it would be incorrect to say that all the
clauses including Clause 10 would cease to operate after the period of
operation had come to an end. It being the clear intent that such stages
and eventualities ought to survive even after the expiry of the Scheme,
we reject the submission advanced on behalf of the State.
17. Clause 7 of the Scheme classifies projects in different
categories and for a Large Scale Tourism Unit, with which we are
presently concerned, fixed capital investment was required to be
more than Rs.90 lakhs. The Scheme definitely promised an initial
period for completion of the project under Clause 10 (a) as two years
after the initial effective steps were under taken by the concerned unit.
Clause 10 (b) further promised an extension for two years subject to
State Level Committee being satisfied that an individual unit had
experienced difficulties in implementing the project. A unit was
therefore promised the availability of an opportunity, depending upon
20
Page 21
the individual fact situation, to pray for extension up to two years.
Clause 10(C) further entitled such unit to approach the State Govt.
even after the aforesaid aggregate period of four years for further
extension. In our view, Clause 10 was one of the core features of the
Scheme based on which eligible units were invited to make capital
investment of more than Rs. 90 Lakhs with a promise of incentives
under Clause 8. Having given such promise, based on which the
appellants incurred capital expenditure, the question now arises as
regards applicability of doctrine of Promissory Estoppel.
18. The law on the subject of Promissory Estoppel was recapitulated
and succinctly dealt with by this Court in State of Punjab Vs. Nestle
India Ltd.1 It found the foundation of the doctrine laid in the decision
in Collector of Bombay Vs. Municipal Corporation of the City of
Bombay2, the principle built upon in Union of India Vs. Anglo
Afghan Agencies3 and the superstructure of the doctrine, with its
pre-conditions, strengths and limitations outlined in the decision in
Motilal Padampat Sugar Mills Co. Ltd. Vs. State of UP4. This
Court then dealt with the discordant note in Jit Ram Vs. State of
1 2004(6) SCC 465 2 1952 SCR 43 3 1968(2) SCR 366 4 1979(2)SCC 409
21
Page 22
Haryana5 and how that was firmly disapproved in Union of India Vs.
Godfrey Philips India Ltd.6 by a bench of three judges. We deem it
appropriate to quote paras 27, 28, 29, 34, 35 and 36 from the decision
in State of Punjab Vs. Nestle India Ltd. (Supra):-
“27. However, the superstructure of the doctrine with its preconditions, strengths and limitations has been outlined in the decision of Motilal Padampat Sugar Mills Co. Ltd. v. State of U.P.3 Briefly stated: the case related to a representation made by the State Government that the petitioners’ factory would be exempted from payment of sales tax for a period of three years from the date of commencement of production. It was proved that the petitioners had, as a consequence of the representation, set up the factory in the State. But the State Government refused to honour its representation. It claimed sales tax for the period it had said that it would not. When the petitioners went to court, the State Government took the pleas:
(1) in the absence of notification under Section 4-A, the State Government could not be prevented from enforcing the liability to sales tax imposed on the petitioners under the provisions of the Sales Tax Act;
(2) that the petitioners had waived their right to claim exemption; and
(3) that there could be no promissory estoppel against the State Government so as to inhibit it from formulating and implementing its policies in public interest.
5 1981(1)SCC 11 6 1985(4) SCC 369
22
Page 23
28. This Court rejected all the three pleas of the Government. It reiterated the well-known preconditions for the operation of the doctrine:
(1) a clear and unequivocal promise knowing and intending that it would be acted upon by the promisee;
(2) such acting upon the promise by the promisee so that it would be inequitable to allow the promisor to go back on the promise.
29. As for its strengths it was said: that the doctrine was not limited only to cases where there was some contractual relationship or other pre-existing legal relationship between the parties. The principle would be applied even when the promise is intended to create legal relations or affect a legal relationship which would arise in future. The Government was held to be equally susceptible to the operation of the doctrine in whatever area or field the promise is made — contractual, administrative or statutory. To put it in the words of the Court:
“The law may, therefore, now be taken to be settled as a result of this decision, that where the Government makes a promise knowing or intending that it would be acted on by the promisee and, in fact, the promisee, acting in reliance on it, alters his position, the Government would be held bound by the promise and the promise would be enforceable against the Government at the instance of the promisee, notwithstanding that there is no consideration for the promise and the promise is not recorded in the form of a formal contract as required by Article 299 of the Constitution. (SCC p. 442, para 24) * * *
[E]quity will, in a given case where justice and fairness demand, prevent a person from insisting on strict legal rights, even where they arise, not under any contract, but on his own title deeds or under statute. (SCC p. 425, para 8)
23
Page 24
* * *
Whatever be the nature of the function which the Government is discharging, the Government is subject to the rule of promissory estoppel and if the essential ingredients of this rule are satisfied, the Government can be compelled to carry out the promise made by it.” (SCC p. 453, para 33)
34. The discordant note struck by Jit Ram case5 was firmly disapproved by a Bench of three Judges in Union of India v. Godfrey Philips India Ltd.6 It was affirmed that: (SCC p. 387, para 12) “12. There can therefore be no doubt that the doctrine of promissory estoppel is applicable against the Government in the exercise of its governmental, public or executive functions and the doctrine of executive necessity or freedom of future executive action cannot be invoked to defeat the applicability of the doctrine of promissory estoppel.” 35. It was held that irrespective of the nature of power wielded the Government is bound to wield that power provided it possessed such power and has promised to do so knowing and intending that the promisee would act on such promise and the promisee has done so: (SCC p. 389, para 14)
“We think that the Central Government had power under Rule 8 sub-rule (1) of the Rules to issue a notification excluding the cost of corrugated fibreboard containers from the value of the cigarettes and thereby exempting the cigarettes from that part of the excise duty which would be attributable to the cost of corrugated fibreboard containers. So also the Central Board of Excise and Customs had power under Rule 8 sub-rule (2) to make a special order in the case of each of the respondents granting the same exemption, because it could legitimately be said that, having regard to the representation made by the Cigarette Manufacturers’ Association, there were circumstances of an exceptional nature which required the exercise of the power under sub-rule (2) of Rule 8. The Central Government and the
24
Page 25
Central Board of Excise and Customs were therefore clearly bound by promissory estoppel to exclude the cost of corrugated fibreboard containers from the value of the goods for the purpose of assessment of excise duty for the period 24-5-1976 to 2-11-1982.”
36. The limitations to the doctrine delineated in
Motilal Padampat Sugar Mills3 however, were also reaffirmed when it was said: (SCC pp. 387-88, para 13) “[T]hat there can be no promissory estoppel against the legislature in the exercise of its legislative functions nor can the Government or public authority be debarred by promissory estoppel from enforcing a statutory prohibition. It is equally true that promissory estoppel cannot be used to compel the Government or a public authority to carry out a representation or promise which is contrary to law or which was outside the authority or power of the officer of the Government or of the public authority to make. We may also point out that the doctrine of promissory estoppel being an equitable doctrine, it must yield when the equity so requires; if it can be shown by the Government or public authority that having regard to the facts as they have transpired, it would be inequitable to hold the Government or public authority to the promise or representation made by it, the Court would not raise an equity in favour of the person to whom the promise or representation is made and enforce the promise or representation against the Government or public authority.”
19. Coming to the facts of the present case, we find that the
Scheme definitely promised incentives in the form of Tax holiday of
5-10 years in respect of exemptions from Sales Tax, Turnover Tax,
Electricity Duty, Luxury Tax and Entertainment Tax upto 100 per cent
25
Page 26
of capital investment if a new unit was registered after 1.8.1995 and
appropriate investment in fixed capital assets was made. It also
promised an initial period of two years for going operational in the
first instance, extendable by further period of two years subject to
satisfactory progress to be found by the State Level Committee. Even
thereafter, the Unit could still approach the State Government for
further extension. This was part of the core of the Scheme, which
invited investment in tourism units promising tax holiday as stated
above. Based on such representation, various units including that of
the appellants having come forward and altered their position, the
State Government would certainly be bound by the principles of
Promissory Estoppel. The State Government was thus estopped from
going back on the promise so made in the Scheme and could not have
curtailed the period and the opportunity specifically made available
within which the project could be completed so as to avail the benefits
under the Scheme.
We find nothing in the present case on the basis of which there
could possibly be room to say that it would be inequitable to hold the
State Government to its promise. Out of 108 TRCs issued under the
Scheme, the burden that the Government was well aware and thought
26
Page 27
that it could comfortably bear, only 19 or 20 units have been
established and are functional. In any case, the impact of incentives
so offered under the Scheme and the consequential burden must have
been weighed carefully when such promise was made and the Scheme
was formed. We may respectfully refer to the following observations
of this Court in S.V.A. Steel Re- Rolling Mills Ltd. and others v.
State of Kerala and others7 to which one of us (Anil R. Dave, J.) was
a party:
“30. Before laying down any policy which would give benefits to its subjects, the State must think about pros and cons of the policy and its capacity to give the benefits. Without proper appreciation of all the relevant factors, the State should not give any assurance, not only because that would be in violation of the principles of promissory estoppel but it would be unfair and immoral on the part of the State not to act as per its promise.”
20. Furthermore, the Scheme as framed on 20.12.1995 formed the
basis of a statutory notification under Section 29 of Act 16 of 1977
and as such the core components of the Scheme had acquired a
statutory status. By virtue of said Section 29, the notification dated
14.2.1997 was required to be laid for not less than 30 days before the
State Legislature. If the State Government was desirous of amending,
7 (2014) 4 SCC 186
27
Page 28
varying or rescinding said notification dated 14.2.1997, the
subsequent G.R. dated 28.06.2000 ought to have been translated in a
statutory notification under Section 29 of the Act 16 of 1977. In the
absence of such steps having been undertaken, G.R. dated 28.06.2000
could not in any way detract from or dilute the effect of the Scheme
which had acquired statutory status.
21. We therefore hold that the appellants were entitled to have full
benefit and advantage of Clause 10 of the Scheme and the curtailment
of the period and opportunity available under said Clause 10 of the
Scheme by subsequent G.R. dated 28.06.2000 was bad and
ineffective.
22. The record indicates that the progress of the project of the
appellants was greatly hampered as a result of major earth quake in
the State on 26.01.2001 and large scale communal riots in the State in
February 2002. The State Level Committee was satisfied that the
commencement and continuation of the project was so affected as a
result of these major difficulties and had granted initial extension of
six months but the appellants had benefit of only few days out of such
extension. The subsequent request for further extension which was
28
Page 29
backed with relevant certificate from the Chartered Accountant
certainly persuaded the State Level Committee to find that the facts
justified grant of further extension but it felt it had lost the power to
grant such extension because of G. R. dated 28.06.2000. In the light
of the view that we have taken, the State Level Committee was still
competent to consider the request for grant of extension.
23. In the circumstances, we allow the appeal and set aside the
decision of the High Court in so far as it held that the operative period
of the Scheme came to an end on 30.11.2000 and that there could be
no further extension of time limit. Since the appellants have already
commenced commercial operations, it now needs to be assessed by
the State Level Committee whether in the facts of the case the
appellants could justifiably have claimed extension under Clause 10
of the Scheme. We direct the State Level Committee to make such
assessment in accordance with Clause 10, in three months of the
receipt of this decision. Needless to say, if such assessment is found in
favour of the appellants, they shall be entitled to the incentives and
benefits under the Scheme.
29
Page 30
24. All the connected matters raise identical issues and challenge
rejection of their applications for extension of time. In each case the
Order passed by the concerned authority is similarly worded and
passed on 20.07.2005, i.e. the same date. These connected appeals are
also allowed with similar direction.
25. The appeals stand allowed in terms as stated above. No order
as to costs.
………………………..J. (Anil R. Dave)
………………………..J. (Uday Umesh Lalit)
New Delhi, May 13, 2015
30